Texas Company (Australasia) Limited (Private) Act 1928

Reprint 1: The Act as at 1 April 2005


Guide for using this reprint

What the reprint includes

Endnotes, Compilation table, and Table of provisions that have not come into operation

1.Details about the original Act and legislation that has amended its text are shown in the Compilation table in endnote 1, at the back of the reprint. The table also shows any previous reprint.

2.Validation, transitional, savings, or other provisions identified in the Compilation table may be important. The table may refer to another endnote setting out the text of these provisions in full.

3.A table of provisions that have not come into operation, to be found in endnote 1a if it is needed, lists any provisions of the Act being reprinted that have not come into operation and any amendments that have not come into operation. The full text is set out in another endnote that is referred to in the table.

Notes amongst text (italicised and within square brackets)

1.If the reprint includes a section that was inserted, or has been amended, since the Act being reprinted was passed, editorial notes at the foot of the section give some history of how the section came to be as it is. If the section replaced an earlier section, no history of the earlier section is given (the full history of the Act is in the Compilation table).

Notes of this kind may also be at the foot of Schedules or headings.

2.The other kind of editorial note shows something has been —

removed (because it was repealed or deleted from the law); or

omitted under the Reprints Act 1984 s. 7(4) (because, although still technically part of the text, it no longer has any effect).

The text of anything removed or omitted can be found in an earlier reprint (if there is one) or one of the written laws identified in the Compilation table.

Reprint numbering and date

1.The reprint number (in the footer of each page of the document) shows how many times the Act has been reprinted. For example, numbering a reprint as “Reprint 3” would mean that the reprint was the 3rd reprint since the Act was passed. Reprint numbering was implemented as from 1 January 2003.

2.The information in the reprint is current on the date shown as the date as at which the Act is reprinted. That date is not the date when the reprint was published by the State Law Publisher and it is probably not the date when the most recent amendment had effect.

 

 

 

Reprinted under the Reprints Act 1984 as

at 1 April 2005

Texas Company (Australasia) Limited (Private) Act 1928

CONTENTS

1.Short title2

2.Interpretation2

3.Limits of the Act3

4.Power to construct works3

5.Notice to be served and plan deposited before breaking up streets etc.4

6.Streets etc. broken up to be reinstated without delay5

7.Penalty for breaking up without notice or delay in reinstating6

8.In cases of delay other parties may reinstate and recover expenses6

9.Company to make compensation for any damage6

10.Power to local authority to alter situation of pipes, etc.7

11.Offences7

12.Damages for accidentally damaging works, etc.8

13.Court in which proceedings to be taken8

14.Payment in lieu of rates etc.8

15.Act to be deemed a public Act9

16.Deposit9

17.Voidance of Act on default of commencement of works9

Notes

Compilation table10

 

 

Crest

Reprinted under the Reprints Act 1984 as

at 1 April 2005

Texas Company (Australasia) Limited (Private) Act 1928

An Act to grant to the Texas Company (Australasia) Limited, powers and provisions for the storage and supply of oil, liquid fuel, petroleum spirits, kerosene and petroleum products, and for other purposes.

Preamble

Whereas the construction of reservoirs and works as hereinafter provided, and the storage, supply and distribution therein, therefrom, and thereby of oil, liquid fuel, petroleum spirits, kerosene and petroleum products within the area hereinafter defined would be of public and local advantage: And whereas The Texas Company (Australasia), Limited, duly formed and registered as a limited company under the Companies Acts in New South Wales is seized and possessed of or entitled to use and possession of North Fremantle Town Lots 52 and 53, and part of Lots 45, 48, 49, and may hereafter acquire other lands within the limits hereinafter mentioned, and is willing and proposes at its own expense to construct and erect thereon the necessary storage tanks, reservoirs, and works for the storage, supply, and distribution of oil, liquid fuel, petroleum spirits, kerosene and petroleum products: And whereas it is desirable and expedient to grant to and confer upon the said company the powers, rights, and privileges hereinafter appearing: Be it therefore enacted by the King’s Most Excellent Majesty, by and with the advice and consent of the Legislative Council and Legislative Assembly of Western Australia, in this present Parliament assembled, and by the authority of the same, as follows: — 

1.Short title

This Act may be cited as the Texas Company (Australasia) Limited (Private) Act 1928 1.

2.Interpretation

In this Act, unless the context otherwise requires — 

Company means the Texas Company (Australasia) Limited 2, and shall include its assigns:

Crown lands includes land vested in the Minister for Lands 3 or any other Minister or person on behalf of the Crown:

Local authority means within their respective jurisdictions the Mayor and Councillors of the Municipality of North Fremantle 4, the Commissioner of Railways 5, and the Fremantle Port Authority:

Railway has the meaning defined by the Government Railways Act 1904:

Street includes any street, highway, land, public road, thoroughfare, passage, footpath, pavement, or place within the area hereinafter defined:

Undertaking means the storage, supply, and distribution of oil, liquid fuel, petroleum spirit, kerosene and petroleum products within the limits herein mentioned, and the making and constructing of all works connected therewith, and all other works authorised by this Act, and the doing of all things necessary or convenient therefor, subject to the provisions of this Act:

Wharf includes any wharf, dock, quay, jetty, landing stage, or other landing place and approaches thereto:

Works means all buildings, erections, storage tanks, reservoirs, works, plant, machinery, apparatus, pipes, mains, connections, and all other works connected with and incidental to the undertaking, or by this Act or in any other way authorised to be constructed or undertaken by the company.

[Section 2 amended by No. 5 of 1999 s. 21.]

3.Limits of the Act

The limits of this Act shall extend to and include the area within the boundaries of the Municipality of North Fremantle 4, and also so much of the area of the lands and property vested in the Fremantle Port Authority as is contained within the inner harbour in the description of the Port of Fremantle under the Port Authorities Act 1999, or which may hereafter be vested in, acquired, or held by, or may be placed or be in the custody, possession, or control of, or over which the Fremantle Port Authority may exercise authority or dominion, and also so much of the area of any Crown lands or lands vested in the Honourable the Minister for Railways or the Minister of the Crown administering the Government Railways Act 1904 6, for the time being respectively as adjoins or abuts on the lands and property of the Fremantle Port Authority above described, or lies between the same lands and property and the boundaries of the Municipality of North Fremantle 4.

[Section 3 amended by No. 5 of 1999 s. 21; No. 74 of 2003 s. 116.]

4.Power to construct works

Subject to the provisions and within the limits of this Act, the company may — 

(a)erect, construct, lay down, establish, and fix all necessary works, and do and perform all such other acts and things as may be thought necessary for storing, supplying, and distributing oil, liquid fuel, petroleum spirits, kerosene and petroleum products in or under any street, or in or under any Crown lands, or in or under any railway or wharf;

(b)open, break up, and interfere with any Crown lands, street, railway, or wharf, and any sewer, water pipe, drain, or tunnel within or under any Crown lands, street, railway, or wharf, and may lay down and place in, on, or under any Crown lands, street, railway, or wharf, mains, conduits, service pipes, and other works for the supply and distribution of oil, liquid fuel, petroleum spirits, kerosene and petroleum products, and also may from time to time repair, alter, or remove the same, and for the purposes aforesaid may remove or use all earth and material in or under such Crown lands, street, railway, or wharf:

Provided that the power to open, break up, or interfere with any Crown lands, railway or wharf shall not be exercised without the consent of the Minister 6 administering the Land Acts or the Government Railways Act 1904, or the Port Authorities Act 1999, respectively, subject to such conditions as the Minister may deem expedient:

Provided, also, that all plans and specifications for the construction of the necessary works for storing and supplying or distributing in or under any street shall first be submitted to and approved of by the Minister for Works 7.

[Section 4 amended by No. 5 of 1999 s. 21.]

5.Notice to be served and plan deposited before breaking up streets etc.

Before the company proceeds to open, break up, or interfere with any Crown lands, street, railway, or wharf, sewer, water pipe, drain, or tunnel it shall give to the Minister or to the local authority concerned notice in writing of its intention so to do not less than 3 clear days before commencing such work, and shall at the same time deposit with the Minister or local authority a plan setting forth the extent to, and the manner in which, it proposes to carry out such work, and the time at which it is intended to commence the same, and (except as hereinafter provided) no Crown lands, street, railway, or wharf, sewer, water pipe, drain, or tunnel shall be opened, broken up, or interfered with unless under the superintendence of the Minister or local authority, and in accordance with the plan deposited as aforesaid:

Provided always that if no officer appointed by the Minister or local authority attends at the time fixed in such notice and remains during the opening, breaking up, or interference with any street, railway, or wharf, sewer, water pipe, drain, or tunnel, the company may perform the work specified in such notice and set out in such plan without such superintendence:

Provided, further, that in cases of emergency arising from accidents to or defects in the works necessitating the opening, breaking up of or interference with any street, railway, or wharf, sewer, water pipe, drain, or tunnel, such accidents or defects may be repaired without previous notice and without the deposit of any plan, but such notice shall be given and such plan shall be deposited as soon as possible after the commencement of the work or the necessity for the same has arisen.

6.Streets etc. broken up to be reinstated without delay

Whenever the company opens, breaks up, or interferes with any Crown lands, street, railway, or wharf, sewer, water pipe, drain, or tunnel, it shall with all convenient speed complete the work and fill in the ground and reinstate and make good the same to the satisfaction of the Minister or local authority, and carry away all rubbish occasioned by the work, and whilst any street, railway, or wharf shall be opened, broken up, or interfered with, the company shall cause the same to be properly guarded and sufficiently lighted for the warning of the public and shall, when and as required by the Minister or the local authority, keep so much of any street, railway, or wharf as has been opened, broken up, or interfered with in good repair for 6 months after replacing and making good the same.

7.Penalty for breaking up without notice or delay in reinstating

If the company commits, permits, or suffers any act, delay, neglect, or omission contrary to the provisions of sections 5 and 6, it shall be guilty of an offence against this Act, and be liable to a penalty not exceeding $100 for every such offence, and an additional penalty of $4 for each day during which any such neglect, omission, or delay shall continue after notice thereof by the Minister or local authority:

Provided that nothing in this section contained shall relieve the company from liability in respect of the right of action or remedy of any person for any act, delay, neglect, or omission on the part of the company contrary to the provisions of sections 5 and 6.

[Section 7 amended by No. 113 of 1965 s. 8(1).]

8.In cases of delay other parties may reinstate and recover expenses

If any such delay, neglect, or omission as aforesaid take place, the Minister or local authority may cause the work so delayed, neglected, or omitted, to be executed and performed, and all expenses so incurred shall be repaid to such Minister or local authority by the company:

Provided that nothing in this section contained shall render it compulsory for the Minister or local authority to execute or perform any such work, or render it liable for delay, neglect, or failure so to do.

9.Company to make compensation for any damage

The company shall do as little damage as may be in the execution of the powers conferred by this Act, and shall make compensation for any damage which may be done in the execution of such powers.

10.Power to local authority to alter situation of pipes, etc.

If at any time the Minister or the local authority deems fit, necessary, or expedient to require the company to raise, sink, or otherwise alter the situation of any works which shall have been erected, constructed, laid down, or fixed contrary to any of the provisions of this Act, or in breach of any condition imposed by the Minister as provided in section 4, or for any other reason, then the company shall, within a reasonable time after being required so to do by notice in writing, raise, sink, or otherwise alter the situation of such works accordingly, and in default it shall be lawful for the Minister or the local authority to cause such works to be so raised, sunk, or the situation thereof otherwise altered, and the expenses thereof shall, if rendered necessary by reason of a breach by the company of any of the provisions of this Act or of any such condition as aforesaid or any other default of the company, be borne and paid by the company and shall, in any other case, be borne and paid by the Minister or the local authority:

Provided that if, in raising, sinking, or otherwise altering the situation of any of the works for any reason other than a breach by the company of any of the provisions of this Act, any injury shall be done to the same by any person employed by the local authority, compensation shall be made by the local authority to the company for such injury.

11.Offences

Any person who — 

(a)lays or causes to be laid any pipe to connect with any pipe belonging to the company without the consent of the company first had and obtained for that purpose; or

(b)wilfully or by negligence removes, destroys, or damages any part of the works or other property of the company; or

(c)alters the index to any meter or other recording or measuring apparatus for registering the quantity of oil, liquid fuel, petroleum spirits, kerosene or petroleum products supplied; or

(d)erects or keeps erected any apparatus or fitting whereby oil, liquid fuel, petroleum spirits, kerosene or petroleum products may be obtained from any part of the works of the company without the consent in writing of the company first had and obtained for that purpose,

shall be guilty of an offence against this Act, and shall, without prejudice to any other right or remedy of the company to recover damages, be liable to a penalty not exceeding $10 for every such offence.

[Section 11 amended by No. 113 of 1965 s. 8(1).]

12.Damages for accidentally damaging works, etc.

Every person who unlawfully or wrongfully breaks, throws down, or damages any of the works the property of the company or under its control, shall pay to the company full compensation for such damage, which compensation may be recovered by the company in any court of competent jurisdiction.

13.Court in which proceedings to be taken

All penalties in respect of offences under this Act may be recovered in a court of summary jurisdiction.

14.Payment in lieu of rates etc.

The mains, conduits and service pipes of the company in, on, or under any Crown lands, street, railway, or wharf shall be deemed to be rateable land, but in lieu of the provisions of the Municipal Corporations Act 1906 8, relating to the valuation of land and the making of rates in respect thereof, the company shall pay to the Council in each and every year of the company’s operations subsequent to the date on which it shall commence to construct its works and undertakings, a sum of $70.

The amount to be paid by the company under this section shall be paid by half‑yearly payments, the first of which shall be made on the expiration of 6 months from the date on which the company shall commence to construct its works and undertakings, and shall be in full satisfaction and discharge of all rates and rents, if any, payable to the council in respect of such mains, conduits and service pipes in, on, or under any Crown lands, street, railway, or wharf as aforesaid or the easement or rights conferred by this Act with regard to such mains, conduits and service pipes.

In this section Council means the Mayor and Councillors of the Municipality of North Fremantle 4.

[Section 14 amended by No. 113 of 1965 s. 8(1).]

15.Act to be deemed a public Act

This Act shall be deemed and taken to be a public Act, and shall be judicially taken notice of as such by all judges, justices, and others within the said State of Western Australia, without being specially pleaded.

16.Deposit

The money deposited by the company with the Treasurer, in accordance with the Joint Standing Orders relating to Private Bills, shall be held by the Treasurer until completion of the work aforesaid, and thereupon be returned to the company.

17.Voidance of Act on default of commencement of works

If the company shall not commence before 1 January 1931, any of the works authorised to be constructed or undertaken by the company, this Act shall cease and determine.

dline

 

Notes

1This reprint is a compilation as at 1 April 2005 of the Texas Company (Australasia) Limited (Private) Act 1928 and includes the amendments made by the other written laws referred to in the following table. The table also contains information about any reprint.

Compilation table

Short title

Number and year

Assent

Commencement

Texas Company (Australasia) Limited (Private) Act 1928

1928 (19 Geo. V)

28 Dec 1928

28 Dec 1928

Decimal Currency Act 1965

113 of 1965

21 Dec 1965

Act other than s. 4-9: 21 Dec 1965 (see s. 2(1));
s. 4-9: 14 Feb 1966 (see s. 2(2))

Port Authorities (Consequential Provisions) Act 1999 s. 21

5 of 1999

13 Apr 1999

14 Aug 1999 (see s. 2 and Gazette 13 Aug 1999 p. 3823)

Statutes (Repeals and Minor Amendments) Act 2003 s. 116

74 of 2003

15 Dec 2003

15 Dec 2003 (see s. 2)

Reprint 1: The Texas Company (Australasia) Limited (Private) Act 1928 as at 1 Apr 2005 (includes amendments listed above)

2As at the date of this reprint the name of the company was Caltex Petroleum Pty Ltd.

3At the date this reprint was prepared the title of the Minister responsible for land administration was the Minister for Planning and Infrastructure.

4The Municipality of North Fremantle became part of the City of Fremantle on 1 Nov 1961.

Under the Local Government Act 1995 Sch. 9.3, municipal districts existing as at 1 July 1996 continued as districts under that Act and municipalities continued as local governments. Under Sch. 9.3 cl. 3(2) a reference to a municipality may, where the context so requires, be read as if it had been amended to include or be a reference to a local government under that Act.

5The former Commissioner of Railways has been replaced by the Public Transport Authority of Western Australia.

6As at the date this reprint was prepared the title of the Minister administering these Acts was the Minister for Planning and Infrastructure.

7At the date this reprint was prepared, the former Minister for Works was known as the Minister for Housing and Works.

8Repealed by the Local Government Act 1960, the relevant provisions of which were repealed by the Local Government Act 1995.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

By Authority: JOHN A. STRIJK, Government Printer